Terms of Service

Last Updated: 03/25/2026

PLEASE READ THESE TERMS OF SERVICE CAREFULLY BEFORE ENGAGING THE SERVICES OF

PSP CUSTOM GARAGE BUILDERS LTD.

1. ACCEPTANCE OF TERMS

By requesting a quote, entering into a contract, or otherwise engaging the

services of PSP Custom Garage Builders Ltd. ("PSP," "we," "our," or "us"), you

("Client," "you," or "your") agree to be bound by these Terms of Service

("Terms"). If you do not agree to these Terms, do not engage our services.

These Terms constitute a legally binding agreement between you and PSP Custom

Garage Builders Ltd., a company incorporated and operating in the Province of

Saskatchewan, Canada.

2. SERVICES

PSP Custom Garage Builders Ltd. provides custom garage design, construction,

and related services in Saskatchewan. The specific scope of work, materials,

timelines, and pricing applicable to your project will be set out in a separate

written contract or agreement ("Project Agreement") provided to you prior to

commencement of work.

In the event of any conflict between these Terms of Service and a Project

Agreement, the terms of the Project Agreement shall prevail with respect to

the specific project.

3. QUOTES AND ESTIMATES

All quotes and estimates provided by PSP are valid for thirty (30) days from

the date of issue unless otherwise stated in writing. Quotes are based on

information available at the time of preparation. Changes to project scope,

site conditions, material availability, or applicable regulations may result

in adjusted pricing. PSP reserves the right to revise a quote if material

inaccuracies in the provided information are discovered.

4. CONTRACTS AND PROJECT AGREEMENTS

No work will commence until a written Project Agreement has been signed by

both parties and any required deposit has been received. Project Agreements

will outline the scope of work, payment schedule, project timeline, warranty

information, and any applicable special terms.

5. PAYMENT TERMS

Payment terms are as specified in the Project Agreement. Unless otherwise

agreed in writing:

(a) A deposit is required prior to commencement of work, the amount of

which will be specified in the Project Agreement;

(b) Progress payments may be required at stages specified in the Project

Agreement;

(c) Final payment is due upon substantial completion of the project;

(d) Overdue balances may be subject to interest charges at a rate of 2%

per month (24% per annum), compounded monthly.

Failure to make timely payments may result in suspension of work without

liability to PSP.

6. CHANGES AND VARIATIONS

Any changes to the agreed scope of work must be requested in writing and

approved by PSP. PSP will provide a written change order outlining the impact

on cost and timeline before proceeding. Work on changes will not commence

until the change order is signed and, where applicable, an additional deposit

is received.

7. CLIENT RESPONSIBILITIES

You agree to:

(a) Provide accurate information regarding the project site, intended use,

and any relevant existing structures;

(b) Obtain and maintain any required permits, approvals, or authorizations

from applicable municipal or provincial authorities, unless PSP has

expressly agreed in writing to obtain such permits on your behalf;

(c) Ensure PSP and its subcontractors have safe, unobstructed access to the

project site during agreed working hours;

(d) Notify PSP promptly of any site conditions that may affect the work,

including underground utilities, environmental concerns, or structural

issues;

(e) Ensure that the project site complies with all applicable zoning bylaws

and land use regulations.

8. PERMITS AND REGULATORY COMPLIANCE

PSP will construct all garages in accordance with applicable Saskatchewan

building codes and regulations. Unless explicitly agreed otherwise in writing,

responsibility for obtaining building permits and complying with local

municipal requirements rests with the Client. PSP is not responsible for

project delays or cost increases resulting from permitting delays or

regulatory changes outside of PSP's control.

9. SUBCONTRACTORS

PSP may engage qualified subcontractors to perform portions of the work. PSP

remains responsible for ensuring that subcontracted work meets the standards

set out in the Project Agreement.

10. WARRANTY

PSP warrants its workmanship against defects for a period as specified in the

Project Agreement. This warranty does not cover:

(a) Damage caused by misuse, neglect, or failure to maintain;

(b) Normal wear and tear;

(c) Damage caused by third parties or Acts of God;

(d) Manufacturer defects in materials (which are subject to the applicable

manufacturer's warranty).

Warranty claims must be submitted in writing to [email protected]

within the applicable warranty period.

11. LIMITATION OF LIABILITY

To the maximum extent permitted by applicable Saskatchewan and Canadian law,

PSP's total liability for any claim arising out of or relating to the services

shall not exceed the total amount paid by you to PSP under the applicable

Project Agreement.

PSP shall not be liable for indirect, incidental, consequential, special, or

punitive damages, including but not limited to loss of use, loss of profits,

or loss of business opportunity, even if PSP has been advised of the

possibility of such damages.

Nothing in these Terms limits or excludes liability that cannot be limited or

excluded under applicable law, including the Consumer Protection and Business

Practices Act (Saskatchewan) or other applicable consumer protection

legislation.

12. FORCE MAJEURE

PSP shall not be in breach of these Terms or a Project Agreement, nor liable

for any delay or failure to perform its obligations, where such delay or

failure results from events beyond PSP's reasonable control, including but not

limited to acts of God, extreme weather, labour disputes, material shortages,

supply chain disruptions, government orders, or other circumstances beyond

PSP's control.

13. DISPUTE RESOLUTION

In the event of a dispute arising from these Terms or a Project Agreement,

the parties agree to first attempt resolution through good-faith negotiation.

If negotiation fails within thirty (30) days, either party may pursue

resolution through mediation or, if necessary, through the courts of

Saskatchewan. These Terms shall be governed by and construed in accordance

with the laws of the Province of Saskatchewan and the federal laws of Canada

applicable therein.

14. AMENDMENTS

PSP reserves the right to update these Terms of Service at any time. Updated

Terms will be posted on our website. Continued engagement of our services

following notice of any changes constitutes acceptance of the revised Terms.

15. CONTACT

For questions regarding these Terms of Service, please contact:

PSP Custom Garage Builders Ltd.

Saskatchewan, Canada

Phone: 306-585-2457

Email: [email protected]